ADVOKS GLOBAL · KENYA
Engineers (Scale of Fees for Professional Engineering Services) Rules
12. Additional professional engineering services of a general nature
Edition: 2022-12-31 · In force
12. Additional professional engineering services of a general nature
The additional professional engineering services to be provided by an engineer or firm, if requested or consented to by the client, include—(a)enquiries not directly concerned with the works and its subsequent utilisation;(b)preparing any report or other additional documents required for consideration of proposals for the carrying out of alternative works;(c)carrying out work in connection with any additional application made by the client for any order, sanction, licence, permit or other consent, formal approvals, or authorisation necessary to enable the works to proceed including the making of such revisions as may be required as result of changes in policy, undue delay, or other causes beyond the engineer’s or firm’s control;(d)carrying out works and services arising from the failure of a client, contractor or any other relevant person to perform the required duties adequately and in a timely fashion;(e)additional services, duties or work resulting from project scope changes, alterations or instructions by the client, or the client’s duly authorized agents, requiring the engineer or firm to advise upon, review, adapt or alter completed designs or any other documentation or change the scope of services or duties;(f)checking and advising on any part of the project not designed by the engineer or firm or reviewing the work of another engineer or firm;(g)preparing interim or other reports or detailed valuations including estimates or cost analysis based on measurement or forming an element of a cost planning service;(h)carrying out detailed inspection, reviewing and checking of designs and drawings, preliminary estimates for works not prepared by the engineer or firm and submitted by architects, quantity surveyors, contractors and other parties other than those contained in tender or similar documents prepared by the engineer or firm;(i)carrying out any works after abandonment of a contract by the contractor or upon the failure of the contractor to properly perform any contract or upon delay by the client in fulfilling his obligations or in taking any other step necessary for the due execution of the works;(j)advising the client and carrying out works after taking any steps in or towards any litigation or arbitration relating to the works;(k)negotiating any contract or sub-contract with a contractor selected other than by competitive tendering including checking and agreeing on the quantities and net costs of materials and labour, arithmetical checking and agreeing on the added percentages to cover overhead costs and profit;(l)providing project management services or construction management services;(m)carrying out special cost investigations or detailed valuations including estimates or cost analysis based on measurement or forming an element of a cost planning service;(n)preparing drawings for manufacture and installation or detailed checking of such for erection or installation of works as well as detailed operation and maintenance manuals and other documents describing the design and operation of the works;(o)preparing builder’s work drawings, record drawings or any detailed schedules where necessary; and(p)any other additional services of whatever nature specifically agreed to in writing between the engineer or firm and the client.